Terms and Conditions

Effective Date: September 3, 2024

True Value Roofing

Phone: +61 3 4320 5296

Email: [email protected]

1. Acceptance of Terms

By accessing or using the services of True Value Roofing (the "Company", "we", "us", or "our"), you agree to be bound by these Terms and Conditions. If you do not agree, please do not use our services.

2. Services Provided

We provide roofing services, including but not limited to roof installation, repairs, and maintenance. Details of our services can be found on our website or provided upon request.

3. Quotes and Payments

All quotes provided are estimates and may be subject to change based on site conditions.Payment terms will be outlined in the service agreement and may require a deposit prior to the commencement of work.

4. Pricing, Promotions & Quotations

All prices provided by True Value Roofing are calculated based on the specific scope of works, roof size, condition, access requirements, and other relevant project factors.

From time to time, True Value Roofing may advertise promotional offers, discounts, or pricing campaigns (including fixed dollar or percentage-based offers). Unless expressly stated otherwise in writing, such promotions are already incorporated into the pricing provided and are not applied as additional discounts on top of any quote.

Any advertised pricing, starting prices, or promotional offers are indicative only and subject to change based on site inspection and final scope of works.

Quotes issued by True Value Roofing are:

  • Based on the information available at the time of quoting

  • Valid for the period stated in the quote

  • Provided as a complete and final price for the agreed scope of works

True Value Roofing reserves the right to amend pricing where:

  • Additional works are required due to unforeseen conditions

  • The scope of works changes

  • Site conditions differ from those initially disclosed or observed

No verbal representations or assumptions regarding discounts, offers, or pricing will be binding unless confirmed in writing by True Value Roofing.

5. Customer Responsibilities

You agree to provide us with accurate and complete information necessary for us to provide our services. You are responsible for ensuring that our work site is accessible and safe.

6. Warranty and Liability

We offer a warranty on our services, the details of which will be provided in your service agreement. Our liability for any loss or damage arising from our services is limited to the maximum extent permitted by law.

7. Intellectual Property

All content on our website, including text, graphics, and logos, is the property of True Value Roofing and is protected by copyright and other intellectual property laws.

8. Governing Law

These Terms and Conditions are governed by the laws of Victoria, Australia. Any disputes will be resolved in the courts of Victoria.

9. Changes to Terms

We may update these Terms and Conditions from time to time. Changes will be effective when posted on our website.

10. Special Offers for Roof Restoration Services

By participating in any special offer provided by True Value Roofing, you agree to the following Terms and Conditions:

  1. Limited Availability: All offers are available while stocks last and may be withdrawn at any time without prior notice.

  2. Discount Application: Any discounts offered are applied at the time of order and cannot be added retrospectively.

  3. Exclusivity: Offers are not valid in conjunction with any other offer, including interest-free payment plans, unless expressly stated otherwise.

  4. Pricing: Prices, discounts, and savings are subject to change at any time without notice. Any quoted prices are only valid at the time of the offer.

  5. $0 Deposit Policy: For offers that include a $0 deposit, payment is only required once the job is completed to an acceptable standard and the customer is satisfied with the work. This applies exclusively to the services outlined in the agreed work order.

  6. Work Completion Standard: True Value Roofing commits to delivering services to an acceptable industry standard. The final payment is contingent upon the completion of the work as specified in the contract and meeting the customer’s reasonable expectations.

  7. Work Order Precedence: The scope of the job is strictly limited to what is specified in the signed work order. Any additional work or services outside of the agreed terms must be negotiated separately. The work order takes precedence over any verbal or implied agreements.

11. Roof Restoration Guarantee

True Value Roofing guarantees to complete your roof restoration within 7 days from the start of physical work on the roof (not the day of safety rail installation), or you’ll receive $500. Exclusions include delays due to bad weather, illness, acts of God, customer-related issues, unforeseen circumstances, or third-party delays. If these don’t apply, the $500 will be paid within 14 business days.

12. Contact Us

For any questions regarding these Terms and Conditions, please contact us at:

True Value Roofing

Phone: +61 3 4320 5296

Email: [email protected]